Welcome to interiordesignagency.ae (“we”), operated from 10th Floor, Concord Tower, Dubai Media City, Dubai, UAE. These Terms of Service (“Terms”) govern your access to and use of our website and our interior design agency services, including residential design, corporate and office planning, retail and hospitality design, 3D visualization and rendering, material and furniture selection, and spatial planning and consultancy.
By accessing our website or engaging our services, you agree to be bound by these Terms. If you do not agree, please do not use our website or services.
We provide professional interior design agency services, including but not limited to:
Design concept development and creative direction for residential, corporate, retail, and hospitality spaces; spatial planning and layout consultancy; 3D visualization and rendering of proposed designs; sourcing and selection of materials, furniture, fixtures, and finishes; and coordination with contractors, engineers, and suppliers during project execution.
The specific scope of services for any project will be defined in a separate proposal or service agreement agreed between us and the client.
Each project begins with an initial consultation to understand the client’s vision, requirements, and budget. The scope of work, deliverables, fees, and timeline will be set out in a proposal, quotation, or service agreement, which forms part of these Terms once accepted by both parties.
We reserve the right to accept or decline any project at our discretion.
Fees for our services will be communicated in advance via a quotation or proposal and may be structured as a fixed fee, percentage-based fee, or milestone-based payment schedule, as agreed in the relevant service agreement.
Late payments may result in suspension of services, including design work, procurement, and on-site coordination, until outstanding amounts are settled. All fees are exclusive of applicable UAE VAT unless stated otherwise.
The client agrees to review and provide timely approvals or feedback on design concepts, drawings, material selections, and 3D visualizations to avoid delays to the project.
The client is also responsible for providing accurate information regarding the property, budget, and requirements, and for obtaining any necessary approvals, permits, or authorizations from relevant authorities, landlords, or developers.
We are not responsible for delays or additional costs arising from incomplete, inaccurate, or delayed approvals, feedback, or information from the client.
Any changes requested by the client after a design concept, drawing, or specification has been approved may incur additional fees and may affect the project timeline. We will notify the client of any such impact before proceeding with the change.
Where we coordinate with or recommend contractors, suppliers, or tradespeople, we are not responsible for the quality, timeliness, workmanship, or conduct of any third party engaged by the client. Any contracts for construction, supply, manufacturing, or installation are between the client and the relevant third party.
Procurement timelines, particularly for imported materials and bespoke furnishings, are subject to supplier lead times and availability, which are outside our control.
All design concepts, drawings, 3D visualizations, specifications, and other materials produced by us during a project remain our intellectual property until full payment of all fees due has been received, at which point usage rights will be granted as specified in the relevant service agreement.
Our website content, including text, images, logos, portfolio images, and branding, is owned by us or our licensors and may not be copied, reproduced, or distributed without prior written consent.
To the fullest extent permitted under UAE law, we shall not be liable for any indirect, incidental, special, or consequential damages, including loss of profits, loss of property value, or construction-related losses, arising from our design services.
Our total liability for any claim arising from our services shall not exceed the total fees paid by the client for the specific project giving rise to the claim.
Our services involve professional design judgment and recommendations; we do not guarantee specific outcomes, including property valuation increases, project timelines achieved by third-party contractors, or the final results of construction or installation work carried out by other parties.
Where our services involve site visits, the client is responsible for ensuring the site is safe and accessible. We accept no liability for accidents, injuries, or damage occurring on-site that are not directly caused by our negligence.
Both parties agree to keep confidential any proprietary, financial, or personal information shared during the course of a project, except where disclosure is required by law or necessary to perform the services (e.g., sharing specifications with suppliers or contractors).
Unless the client requests otherwise in writing, we reserve the right to feature completed projects, including photographs, 3D visualizations, and general descriptions, in our portfolio, website, and marketing materials.
Either party may terminate a project in accordance with the notice period specified in the relevant service agreement. Fees for work completed and costs incurred up to the date of termination, including any committed procurement orders, remain payable.
We reserve the right to terminate a project immediately if the client breaches these Terms, fails to make payment, or engages in conduct that is abusive, illegal, or unsafe.
You agree to use this website only for lawful purposes and not to engage in any conduct that could damage, disable, or impair the website or interfere with other users’ access.
We make reasonable efforts to ensure the accuracy of information on this website but do not guarantee that all content, including portfolio descriptions and testimonials, is free of errors.
Your use of our website and services is also governed by our Privacy Policy, which explains how we collect, use, and protect your personal data, including information submitted through our contact forms and consultation requests.
These Terms shall be governed by and construed in accordance with the laws of the United Arab Emirates and the applicable regulations of the Emirate of Dubai. Any disputes arising from these Terms or our services shall be subject to the exclusive jurisdiction of the courts of Dubai, UAE.
We reserve the right to update or modify these Terms at any time. Changes will be posted on this page with an updated “Last Updated” date. Continued use of our website or services after such changes constitutes acceptance of the revised Terms.
If you have any questions about these Terms, please contact us at:
interiordesignagency.ae
10th Floor, Concord Tower, Dubai Media City, Dubai, UAE
Email: sales@interiordesignagency.ae
Phone: +971 4 490 2175
